Sealed bids for Island View Park improvements due by March 2, 2026.

FRANKLIN COUNTY ISLAND VIEW PARK FRDAP IMPROVEMENTS PROJECT # 50189044 NOTICE TO RECEIVE SEALED BIDS The Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: FRANKLIN COUNTY ISLAND VIEW PARK FRDAP IMPROVEMENTS Projects Description: Additions to Island View Park which consist of approximately 743 sq ft of concrete pad for modular restroom and covered pavilion, A 16x30 pre-engineered pole barn for the pavilion cover, a modular restroom facility and utility connections, etc. Island View Park is located approximately 1.8 miles east of Carrabelle, Florida. Electronic copies of the Plans and Specifications can be obtained by contacting Sherry Gayheart at sgayheart@dewberry.com or at 850.354.5408. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day. Please indicate on the envelope that this is a sealed bid, for Franklin County Island View Park FRDAP Improvements. Bids will be received until 4:00 p.m. eastern time, on March 2, 2026, at the Franklin County Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, and will be opened and read aloud on March 4, 2026 at the County Commission meeting at 34 Forbes Street, Apalachicola, FL. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. Franklin County encourages Minority Business Enterprises to respond to this Bid Invitation. A mandatory pre-bid meeting will be held at the project site on February 19th, 2026, at 10:00 am eastern time. If you have any questions, please call Erin Griffith at (850) 653-5143. All technical questions must be addressed in writing and emailed to Erin Griffith at erin@franklincountyflorida.com no later than February 23, 2026. Pub: 1/28, 2/4/2026; #12021635